632 PARKS 



agree, that they will well and truly save and indemnify and keep harmless, the said City of Milwaukee, against 

 all liabi'ity, judgments, costs and expenses, which may in any wise come against said city in consequence of the 

 granting of this contract to the said party of the first part, or which may in any wise result from the carelessness 

 or neglect of the said party of the first part, or the agents, employees or workmen of said party of the first part, 

 in any respect whatever, and in every such case whe-e judgment is recovered against the city by reason of the 

 carelessness or negligence of such person, persons, firm or corporation so contracting, or his, their or its agents, 

 employees or workmen, and when due notice has been given of the pendency of such suit, such judgment shall 

 be conclusive against such person, persons, firm or corporation, and his, or their, or its sureties on such bond, 

 not only as to the amount of damages, but as to their liability to said city, and that in case the said party of the 

 first part shall fail to fully and completely perform this contract within the time herein limited for the perform- 

 ance thereof, they shall and will pay to the said City of Milwaukee, as liquidated damages for such default, the 



sum of 



dollars per day for each and every day's delay in completing said contract, after the expiration of the time herein 

 limited for its completion. 



The Board of Park Commissioners may extend the time for the performance of this contract without the 

 consent of the surety or sureties herein. 



This contract is, by consent of all parties hereto, made expressly subject to all the provisions of Chapter 261 

 of the laws passed at the session of the legislature of Wisconsin in the year 1882, entitled "An Act to Amend 

 Chapter 332 of the Laws of 1878, entitled an Act to P-otect Laborers and Material Men in the City of Milwaukee." 



And it is hereby agreed and declared that this contract is made expressly subject to the powers given to 

 said Board of Park Commissioners by Chapter 179 of the laws of the State of Wisconsin of the year 1891, and 

 all subsequent amendments thereto. 



The party of the first part hereby agreed to pay all claims for work and labor performed, and materials 

 furnished for, or in, or about or under this contract, and to comply and be subject to the ordinances of the City 

 of Milwaukee and all subsequent amendments thereto and to ordinances and resolutions relating to a prevailing 

 minimum wage scale and hours of labor of laborers and skilled laborers employed by contractors and sub-con- 

 tractors on all public work. 



The contractor and sureties hereby further agree for themselves, their heirs, executors, administrators, suc- 

 cessors, or assigns, as the case may be, to procure and maintain at their own expense, insurance insuring against 

 all liability under the Workmen's Compensation Law of Wisconsin and to comply with all the terms and pro- 

 visions of said law, and also to indemnify and save harmless the City of Milwaukee against any and all costs, 

 expense or liability of any kind that may be incurred by said city because of any injuries or occupational disease 

 sustained by any employee or employees of the contractor. 



IN WITNESS WHEREOF, the said parties of the first and second parts hereunto set their hands and 

 seals, and the said City of Milwaukee has caused these presents to be subscribed by the said Board of Park Com- 

 missioners, the day and the year first above written, and countersigned by the Comptroller of said city. 



[SEAL] 



....[SEAL) 



Sealed and delivered in presence of 



.[SEAL] 

 .[SEAL] 

 .[SEAL] 



Park Commissioners 



_ Countersigned this day of 



Comptroller. 



STATE OF WISCONSIN 1 

 County of Milwaukee J 



of the City of Milwaukee, being severally duly sworn, severally say and each for himself saith that he is the person 

 of that name who signed the above and foregoing contract as surety, that he is the owner of real estate in the 

 County of Milwaukee, over and above all incumbrances and subject to execution, of a cash value equal to the 



